GVA Granite Construction Inc - 10-K

Item 1A. RISK FACTORS

Set forth below and elsewhere in this report and in other documents we file with the SEC are various risks and uncertainties that could cause our actual results to differ materially from the results contemplated by the forward-looking statements contained in this report or otherwise adversely affect our business.

RISKS RELATED TO OUR BUSINESS

• Unfavorable economic conditions may have an adverse impact on our business. Volatility in the global financial system, deterioration in general economic activity, inflation, rising or high interest rates, tariffs, supply chain issues, wars or other geopolitical tensions, other political, social or economic uncertainties, and fiscal, monetary and other policies that federal, state and local governments may enact, including infrastructure spending or deficit reduction measures, may have an adverse impact on our business, financial position, results of operations, cash flows and liquidity. In particular, low tax revenues, budget deficits, financing constraints, including timing of long-term federal, state and local funding releases, and competing priorities could negatively impact the ability of government agencies to fund existing or new infrastructure projects in the public sector. These factors could have a material adverse effect on the financial market and economic conditions in the United States as well as throughout the world, which may limit our ability and the ability of our customers to obtain financing and/or could impair our ability to execute our strategy.

• We work in a highly competitive marketplace. We have multiple competitors in all the areas in which we work, and some of our competitors are larger than we are and may have greater resources than we do. Government funding for public works projects is limited, contributing to competition. An increase in competition may result in a decrease in new awards, a decrease in profit margins, or both. In addition, should downturns in residential and commercial construction activity occur, the competition for available public sector work would intensify, which could impact our revenue, CAP and profit margins.

• Fixed price and fixed unit price contracts subject us to the risk of increased project cost. As more fully described in “Contract Provisions and Subcontracting” under “Item 1. Business,” the profitability of our fixed price and fixed unit price contracts can be adversely affected by a number of factors, including, among others, inflation, tariffs, inefficiency and incorrect estimates or assumptions, that can cause our actual costs to materially exceed the costs estimated at the time of our original bid. This could result in reduced profits or a loss for that project and there could be a material adverse impact to our business, results of operations and financial condition.

• We derive a substantial amount of our revenue from federal, state and local government agencies, and any disruption in government funding or in our relationship with those agencies could adversely affect our business. For the year ended December 31, 2025, approximately 70% of our construction revenue was funded by federal, state and local government agencies and authorities. A significant amount of this revenue is derived under multi-year contracts, many of which are appropriated on an annual basis. As a result, at the beginning of a project, the related contract may be only partially funded, and additional funding is normally committed only as appropriations are made in each subsequent year. The success and further development of our business depends, in large part, upon the continued funding of these government programs, and upon our ability to obtain contracts and perform well under these programs. A significant reduction in government spending, the absence of a bipartisan agreement on the federal government budget, a partial or full federal government shutdown or a change in budgetary priorities could reduce demand for our services, cancel or delay projects and have a material adverse effect on our business, results of operations and financial condition.

There are several additional factors that could cause government agencies or authorities to delay or cancel programs, to reduce their orders under existing contracts, to exercise their rights to terminate contracts or not to exercise contract options for renewals or extensions. Such factors, which include the following, could have a material adverse effect on our business, financial condition and results of operations or the timing of contract payments from government agencies or authorities:

• the failure of the U.S. government to complete its budget and appropriations process before its fiscal year-end;

Table of Contents

• changes in and delays or cancellations of government programs, procurements, requirements or appropriations;

• budget constraints or policy changes resulting in delay or curtailment of expenditures related to the services we provide;

• re-competes of government contracts;

• the timing and amount of tax revenue received by federal, state and local governments, and the overall level of government expenditures;

• curtailment in the use of government contracting firms;

• delays associated with insufficient numbers of government staff to oversee contracts;

• the preference by government agencies for contracting with small and disadvantaged businesses;

• competing political priorities and changes in the political climate regarding the funding or operation of the services we provide;

• the adoption of new laws or regulations affecting our contracting relationships with the federal, state or local governments;

• unsatisfactory performance on government contracts by us or one of our subcontractors, negative government audits or other events that may impair our relationship with federal, state or local governments;

• a dispute with or improper activity by any of our subcontractors; and

• general economic or political conditions.

• Our U.S. federal government contracts may give government agencies the right to modify, delay, curtail, renegotiate or terminate existing contracts at their convenience at any time prior to their completion, which could have a material adverse effect on our business, financial condition and results of operations. U.S. federal government projects in which we participate as a contractor or subcontractor may extend for several years. Generally, government contracts include the right to modify, delay, curtail, renegotiate or terminate contracts and subcontracts at the government’s convenience any time prior to their completion. Any decision by a U.S. federal government client to modify, delay, curtail, renegotiate or terminate our contracts at their convenience could have a material adverse effect on our business, financial condition and results of operations.

• Our failure to win new contracts and renew existing contracts with private and public sector clients could have a material adverse effect on our business, financial condition and results of operations. Our business depends on our ability to win new contracts and renew existing contracts with private and public sector clients. Contract proposals and negotiations are complex and frequently involve a lengthy bidding and selection process, which is affected by a number of factors. These factors include market conditions, financing arrangements and required governmental approvals. If negative market conditions arise, or if we fail to secure adequate financial arrangements or the required government approval, we may not be able to pursue certain projects, which could have a material adverse effect on our business, financial condition and results of operations.

• The U.S. government may adopt new contract rules and regulations or revise its procurement practices in a manner adverse to us at any time. From time to time, new laws and regulations are enacted, and government agencies adopt new interpretations and enforcement priorities relative to laws and regulations already in effect. Legislation, regulations and initiatives dealing with procurement reform as well as any resulting shifts in the buying practices of U.S. government agencies could have adverse effects on government contractors, including us.

• The timing of new contracts and termination of existing contracts may result in unpredictable fluctuations in our cash flows and financial results. A substantial portion of our revenues are derived from project-based work that is awarded through a competitive bid process. It is generally difficult to predict the timing and geographic distribution of the projects that we will be awarded. The selection of, timing of, or failure to obtain projects, delays in awards of projects, the re-bidding or termination of projects due to budget overruns, cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets, including our fleet of construction equipment, which could lower our overall profitability and reduce our cash flows. Even if we are awarded contracts, we face additional risks that could affect when, or whether, work will begin. This can present difficulty in matching workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a ready workforce and equipment that is larger than necessary, which could have a material adverse effect on our business, financial condition and results of operations. If an expected contract award or the related work release is delayed or not received, we could incur substantial costs without receipt of any corresponding revenues. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments from the customer. Finally, the winding down or completion of work on significant projects that were active in previous periods will reduce our revenue and earnings if such significant projects have not been replaced in the current period.

Table of Contents

Many of our contracts may be canceled upon short notice, typically 30 to 90 days, even if we are not in default under the contract, and we may be unsuccessful in replacing contracts, resulting in a decrease in our revenue, net income and liquidity. Certain of our customers assign work to us on a project-by-project basis under master service agreements. Under these agreements, our customers often have no obligation to assign a specific amount of work to us. Our operations could decline significantly if the anticipated volume of work is not assigned to us or is canceled. Many of our contracts, including our master service agreements, are open to competitive bidding at the expiration of their terms. There can be no assurance that we will be the successful bidder on our existing contracts that come up for re-bid.

• Design-build contracts subject us to the risk of design errors and omissions. Design-build is a common method of project delivery as it provides the owner with a single point of responsibility for both design and construction. We generally subcontract design responsibility to architectural and engineering firms. However, in the event of a design error or omission causing damages, there is risk that the subcontractor or their errors and omissions insurance would not be able to absorb the liability. In this case, we may be responsible, resulting in a potentially material adverse effect on our business, results of operations and financial condition.

• Many of our contracts have penalties for late completion. In some instances, including many of our fixed price contracts, we guarantee that we will complete a project by a certain date. If we subsequently fail to complete the project as scheduled, we may be held responsible for costs resulting from the delay, generally in the form of contractually agreed-upon liquidated damages. In such circumstances, the total cost could exceed our original estimate, which may result in reduced profits or a loss on that project, which could have a material adverse effect on our business, results of operations and financial condition.

• Our failure to adequately recover on affirmative claims brought by us against project owners or other project participants (e.g., back charges against subcontractors) for additional contract costs could have a negative impact on our liquidity and future operations. In certain circumstances, we assert affirmative claims to which we believe we are entitled against project owners, engineers, consultants, subcontractors or others involved in a project for additional costs exceeding the contract price or for amounts not included in the original contract price. These types of affirmative claims occur due to matters such as delays or changes from the initial project scope, both of which may result in additional costs. Often, these affirmative claims can be the subject of lengthy arbitration or litigation proceedings, and it is difficult to accurately predict when and on what terms they will be fully resolved. For additional information, see “ Accounting for our revenues, costs and the valuation of acquired mineral reserves involves significant estimates ” risk factor below. The potential gross profit impact of recoveries for affirmative claims may be material in future periods when they, or a portion of them, become probable and estimable or are settled. When these types of events occur, we use working capital to cover cost overruns pending the resolution of the relevant affirmative claims and may incur additional costs when pursuing such potential recoveries. A failure to recover on these types of affirmative claims promptly and fully could have a negative impact on our business, results of operations and financial condition. In addition, while clients and subcontractors may be obligated to indemnify us against certain liabilities, such third parties may refuse or be unable to pay us.

• Unavailability of insurance coverage could have a negative effect on our operations and results. We maintain insurance coverage as part of our overall risk management strategy and pursuant to requirements to maintain specific coverage that are contained in our financing agreements and in most of our construction contracts. Although we have been able to obtain reasonably priced insurance coverage to meet our requirements in the past, there is no assurance that we will be able to do so in the future, and our inability to obtain such coverage could have an adverse impact on our ability to procure new work, which could have a material adverse effect on our business, results of operations and financial condition.

• An inability to obtain bonding could have a negative impact on our operations and results. As more fully described in “Insurance and Bonding” under “Item 1. Business,” we generally are required to provide surety bonds securing our performance under the majority of our public and private sector contracts. Our inability to obtain reasonably priced surety bonds in the future and, while we monitor the financial health of our insurers and the insurance market, catastrophic events could reduce available limits or the breadth of coverage, both of which could significantly affect our ability to be awarded new contracts and could, therefore, have a material adverse effect on our business, results of operations and financial condition. If we are not able to maintain a sufficient level of bonding capacity in the future, it could preclude our ability to bid for certain contracts or successfully contract with some customers. Additionally, even if we continue to be able to access bonding capacity to sufficiently bond future work, we may be required to post collateral to secure bonds, which would decrease the liquidity we would have available for other purposes.

Table of Contents

• We use certain commodity products that are subject to significant price fluctuations. We are exposed to various commodity price risks relating to, among others, diesel fuel, natural gas, propane, steel, cement and liquid asphalt. We use petroleum-based products, such as fuels, lubricants and liquid asphalt, to power or lubricate our equipment, operate our plants, and as a significant ingredient in the asphaltic concrete we manufacture for sale to third parties and use in our asphalt paving construction projects. We also use steel and other commodities in our construction projects that can be subject to significant price fluctuations due to a number of factors, including inflation and tariffs. Significant price fluctuations could have a material adverse effect on our business, results of operations and financial condition.

• Weather can significantly affect our revenues and profitability. Our ability to perform work is significantly affected by weather conditions such as precipitation and temperature. Changes in weather conditions can cause delays and otherwise significantly affect our project costs. The impact of weather conditions has caused and may continue to cause variability in our quarterly revenues and profitability, particularly in the first and fourth quarters of the year.

• Force majeure events, including natural disasters and terrorists' actions, could negatively impact our business, which may affect our financial condition, results of operations or cash flows. Force majeure or extraordinary events beyond the control of the contracting parties, such as natural and man-made disasters, as well as terrorist actions, could negatively impact the economies in which we operate. We typically negotiate contract language where we are allowed certain relief from force majeure events in private client contracts and review and attempt to mitigate force majeure events in both public and private client contracts. We remain obligated to perform our services after most extraordinary events subject to relief that may be available pursuant to a force majeure clause. If we are not able to react quickly to force majeure events, our operations may be affected, which could have a material adverse effect on our business, results of operations and financial condition.

• Public health events, including health epidemics or pandemics or other contagious outbreaks, could negatively impact our business, financial condition and results of operations. Our ability to perform work may be significantly affected by public health events. If a public health epidemic or pandemic or other contagious outbreak interferes with our ability, or that of our employees, contractors, suppliers, customers and other business partners to perform our and their respective responsibilities and obligations relative to the conduct of our business, our operations may be affected, which could have a material adverse effect on our business, results of operations and financial condition.

• Our CAP is subject to unexpected adjustments and cancellations and could be an uncertain indicator of our future earnings. We cannot guarantee that the revenues projected in our CAP will be realized or, if realized, will be profitable. Projects reflected in our CAP may be affected by project cancellations, scope adjustments, time extensions or other changes. Such changes may adversely affect the revenue and profit we ultimately realize on these projects.

• Economic factors, including inflation, rising and/or high interest rates and tariffs could have an adverse effect on our business, financial condition and results of operations. Our costs were and may continue to be subject to significant inflationary pressures and may be subject to tariff-related price increases, and we may not be able to fully offset such higher costs through price increases. Our inability or failure to do so could have a material adverse effect on our financial position, results of operations, cash flows and liquidity. In addition, increases in or sustained higher interest rates have resulted in and may continue to result in higher interest expense related to borrowings under our Fifth Amended and Restated Credit Agreement (the “Credit Agreement”), which could have a material adverse effect on our business, results of operations and financial condition.

• As part of our growth strategy, we have made and may make future acquisitions, and acquisitions involve many risks and uncertainties. These risks and uncertainties include:

• our ability to complete acquisitions in accordance with our expected plans, on terms and conditions acceptable to us or our anticipated time frame, or at all;

• difficulties identifying all significant risks during our due diligence activities;

• that acquisitions involve significant costs and require the time and attention of our management, which may divert management’s attention from ongoing operations;

• potential difficulties and increased costs associated with completion of any assumed construction projects;

• our ability to successfully manage or achieve the results we expect to experience from the acquisitions and that we may lose key employees or customers of the acquired companies;

• assumption of liabilities of an acquired business, including liabilities that were unknown at the time the acquisition was negotiated;

Table of Contents

• difficulties related to integrating the operations and internal controls, assimilating personnel, services, and systems of an acquired business and to assimilating marketing and other operational capabilities;

• increased burdens on our staff and on our administrative, internal control and operating systems, which may hinder our legal and regulatory compliance activities;

• if we issue additional equity securities, such issuances could have the effect of diluting our earnings per share as well as our existing shareholders’ individual ownership percentages in the Company;

• the recording of goodwill or other non-amortizable intangible assets that will be subject to subsequent impairment testing and potential impairment charges, as well as amortization expenses related to certain other intangible assets; and

• while we often obtain indemnification rights from the sellers of acquired businesses, such rights may be difficult to enforce and the indemnitors may not have the ability to financially support the indemnity.

Failure to successfully manage and integrate acquisitions could harm our business, results of operations and financial condition.

• We may make divestitures, and divestitures involve many risks and uncertainties. These risks and uncertainties include:

• our ability to locate suitable acquirers for our divestitures;

• our ability to complete the divestitures in accordance with our expected plans or anticipated time frame, or at all;

• our ability to complete the divestitures on terms and conditions acceptable to us;

• difficulties separating the assets and personnel related to businesses that we expect to divest from the businesses we expect to retain;

• that divestitures involve significant costs and require the time and attention of our management, which may divert management’s attention from ongoing operations;

• our ability to successfully cause a buyer of a divested business to assume the liabilities of that business, or even if such liabilities are assumed, we may have difficulties enforcing our rights, contractual or otherwise against the buyer;

• the need to obtain regulatory approvals and other third-party consents, which potentially could disrupt customer and vendor relationships;

• potential additional tax obligations or the loss of tax benefits;

• the divestiture could negatively impact our profitability because of losses that may result from a sale, the loss of revenue or a decrease in cash flows; and

• following the completion of a divestiture, we may have less diversity in our business and in the markets we serve as well as our client base.

Failure to successfully manage divestitures may generate fewer benefits than expected and could harm         our business, results of operations and financial condition.

• In connection with acquisitions or divestitures, we may become subject to liabilities. In connection with any acquisitions, we may acquire liabilities or defects such as legal claims, including but not limited to, third party liability and other tort claims; claims for breach of contract; employment-related claims; environmental, health and safety liabilities, conditions or damage; permitting, regulatory or other compliance with law issues; or tax liabilities. If we acquire any of these liabilities, and they are not adequately covered by insurance or an enforceable indemnity or similar agreement from a creditworthy counterparty, we may be responsible for significant out-of-pocket expenditures, which could have a negative impact on our business, financial condition and results of operations. In connection with any divestitures, we may incur liabilities for breaches of representations and warranties or failure to comply with operating covenants under any agreement for a divestiture. We may also retain exposure on financial or performance guarantees, contractual, employment, pension and severance obligations or other liabilities of the divested business and potential liabilities that may arise under law because of the disposition or the subsequent failure of an acquiror. As a result, performance by the divested businesses or other conditions outside of our control could have a material adverse effect on our business, financial condition and results of operations. In addition, we may indemnify a counterparty in a divestiture for certain liabilities of the divested business or operations subject to the divestiture transaction. These liabilities, if they materialize, could have a material adverse effect on our business, results of operations and financial condition.

Table of Contents

RISKS RELATED TO OUR HUMAN CAPITAL, JOINT VENTURES AND SUBCONTRACTORS

• Our success depends on attracting and retaining qualified personnel, joint venture partners and subcontractors in a competitive environment . The success of our business is dependent on our ability to attract, develop and retain qualified personnel, joint venture partners, advisors and subcontractors. Changes in general or local economic conditions and the resulting impact on the labor market and on our joint venture partners may make it difficult to attract or retain qualified individuals in the geographic areas where we perform our work. If we are unable to provide competitive compensation packages, high-quality training programs and attractive work environments or to establish and maintain successful partnerships, our reputation, relationships and/or ability to profitably execute our work could be adversely impacted.

• Failure to maintain safe work sites could result in significant losses . Construction, mining and maintenance sites are potentially dangerous workplaces and often put our employees and others in close proximity with mechanized equipment, moving vehicles, chemical and manufacturing processes, and highly regulated materials. On many sites, we are responsible for safety and, accordingly, must implement safety procedures. If we fail to implement these procedures or if the procedures we implement are ineffective, we may suffer the loss of or injury to our employees, as well as expose ourselves to possible litigation, penalties or fines. Our failure to maintain adequate safety standards through our safety programs could result in reduced profitability or the loss of projects or clients, and could have a material adverse impact on our financial position, results of operations, cash flows and liquidity.

• Strikes or work stoppages could have a negative impact on our operations and results. We are party to collective bargaining agreements covering a portion of our craft workforce. If a strike or work stoppage occurred, it could have a material adverse effect on our operations and results.

• Failure of our subcontractors to perform as anticipated could have a negative impact on our results. As further described in “Contract Provisions and Subcontracting” under “Item 1. Business,” we subcontract portions of many of our contracts to specialty subcontractors, but we are ultimately responsible for the successful completion of their work. Although we seek to require bonding or other forms of guarantees, we are not always successful in obtaining those bonds or guarantees from our higher-risk subcontractors. We may be responsible for the failures on the part of our subcontractors to perform as anticipated, resulting in a potentially adverse impact on our cash flows and liquidity. In addition, the total costs of a project could exceed our original estimates and we could experience reduced profits or a loss for that project, which could have an adverse impact on our financial position, results of operations, cash flows and liquidity.

• Our joint venture contracts subject us to risks and uncertainties, some of which are outside of our control . As further described in Note 1 of “Notes to the Consolidated Financial Statements” and in “Joint Ventures” under “Item 1. Business,” we perform certain construction contracts as a limited or minority member of joint ventures. Participating in these arrangements exposes us to risks and uncertainties, including the risk that if our partners fail to perform under joint and several liability contracts, we could be liable for completion of the entire contract. In addition, if our partners are not able or willing to provide their share of capital investment to fund the operations of the venture, there could be unanticipated costs to complete the projects, financial penalties or liquidated damages. These situations could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.

To the extent we are not the controlling partner, we have limited control over many of the decisions made with respect to the related construction projects. These joint ventures may not be subject to the same compliance requirements, including those related to internal control over financial reporting. While we have controls to mitigate the risks associated with reliance on their control environment and financial information, to the extent the controlling partner makes decisions that negatively impact the joint venture or internal control problems arise within the joint venture, it could have a material adverse impact on our business, financial position, results of operations, cash flows and liquidity.

• We may be unable to identify and contract with qualified DBE contractors to perform as subcontractors. Certain of our government agency projects contain minimum DBE participation clauses. Although we have programs in place to ensure compliance, if we fail to complete these projects with the minimum DBE participation, we may be held responsible for breach of contract, which may include restrictions on our ability to bid on future projects as well as monetary damages. To the extent we are responsible for monetary damages, the total costs of the project could exceed our original estimates, we could experience reduced profits or a loss for that project and there could be a material adverse impact to our financial position, results of operations, cash flows and liquidity.

Table of Contents

• We may be required to contribute cash to meet our unfunded pension obligations in certain multi-employer plans. As of December 31, 2025, three of our wholly-owned subsidiaries, Granite Construction Company, Layne Christensen Company and Granite Industrial, Inc., participate in various domestic multi-employer pension plans on behalf of union employees. Union employee benefits generally are based on a fixed amount for each year of service. We are required to make contributions to certain plans in amounts established under collective bargaining agreements. Pension expense is recognized as contributions are made. The domestic multi-employer pension plans are subject to the Employee Retirement Income Security Act of 1974, as amended (“ERISA”). Under ERISA, a contributor to a multi-employer plan may be liable, upon termination or withdrawal from a plan, for its proportionate share of a multi-employer plan’s unfunded vested liability. While we currently have no intention of withdrawing from a plan and unfunded multi-employer pension obligations have not significantly affected our operations in the past, there can be no assurance that we will not be required to make material cash contributions to one or more of these plans to satisfy certain underfunded benefit obligations in the future.

RISKS RELATED TO LEGAL, REGULATORY, ACCOUNTING AND TAX ISSUES

• Government contractors are subject to suspension or debarment from government contracting. Government contracts expose us to a variety of risks that differ from those associated with private sector contracts. Various statutes and executive orders to which our operations are subject provide for mandatory suspension and/or debarment of contractors in certain circumstances involving statutory violations. In addition, the Federal Acquisition Regulation and various state statutes provide for discretionary suspension and/or debarment in certain circumstances that might call into question a contractor’s willingness or ability to act responsibly, including as a result of being convicted of, or being found civilly liable for, fraud or a criminal offense in connection with obtaining, attempting to obtain or performing a public contract or subcontract. The scope and duration of any suspension or debarment may vary depending upon the facts and the statutory or regulatory grounds for debarment and could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.

• We are involved in lawsuits, legal proceedings and indemnity claims in the ordinary course of our business and may in the future be subject to other litigation, legal proceedings and claims, and, if any of these are resolved adversely against us, it could harm our business, financial condition and results of operations . Any litigation, other legal proceedings or indemnity claim could result in an unfavorable judgment that may not be reversed upon appeal or in payments of substantial monetary damages or fines, or we may decide to settle lawsuits on similarly unfavorable terms, any of which could adversely affect our business, financial condition and results of operations. We could also suffer an adverse impact on our reputation and a diversion of management's attention and resources, which could have a material adverse effect on our business, financial condition and results of operations.

• Government contracts generally have strict regulatory requirements. Approximately 70% of our construction-related revenue in 2025 was derived from contracts funded by federal, state and local government agencies and authorities. Government contracts are subject to specific procurement regulations, contract provisions and a variety of socioeconomic requirements relating to their formation, administration, performance and accounting and often include express or implied certifications of compliance. Claims for civil or criminal fraud may be brought for violations of regulations, requirements or statutes. Additionally, qui tam litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act could require us to pay treble damages. Further, if we fail to comply with any of the regulations, requirements or statutes or if we have a substantial number of accumulated Occupational Safety and Health Administration, Mine Safety and Health Administration or other workplace safety violations, our existing government contracts could be terminated and we could be suspended from government contracting or subcontracting, including federally funded projects at the state level. Should one or more of these events occur, it could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.

• We are subject to environmental, health and safety and other regulation. As more fully described in “Government Regulations” under “Item 1. Business,” we are subject to a number of federal, state, local and foreign laws and regulations relating to the environment, including the remediation of soil and groundwater contamination, emission and discharge of materials into the environment, reclamation and closure of operations, workplace health and safety and a variety of socioeconomic requirements and are required to obtain and maintain a number of approvals, permits, including those relating to barging operations, and financial assurances. Noncompliance with such laws, regulations, approvals, permits and financial assurances can result in, among other things, substantial penalties, or termination or suspension of government contracts or our operations as well as civil and criminal liability. In addition, some environmental laws and regulations impose strict, joint and several liability and responsibility on present and former owners, operators or users of facilities and sites, and

Table of Contents

entities that disposed or arranged for the disposal of hazardous substances at a third-party site, for contamination at such facilities and sites, without regard to causation or knowledge of contamination. We occasionally evaluate various alternatives with respect to our facilities, including possible dispositions or closures. Investigations undertaken in connection with these activities may lead to discoveries of contamination that must be remediated, and closures of facilities may trigger compliance requirements, including reclamation requirements, that may not be applicable to operating facilities. Environmental, health and safety requirements, laws and regulations are becoming increasingly more stringent and there can be no assurance that these requirements, laws or regulations will not change and that compliance with these requirements, laws and regulations will not materially adversely affect our operations in the future. Furthermore, from time to time, we have been involved in remediation activities and we cannot provide assurance that existing or future circumstances or developments with respect to contamination will not require us to make significant remediation or restoration expenditures.

• Increasing restrictions on securing aggregate reserves could negatively affect our future operations and results. Tighter regulations and the finite nature of property containing suitable aggregate reserves are making it increasingly challenging and costly to secure aggregate reserves. Any increasingly difficult permitting process could have a material adverse effect on our business, our financial position, results of operations, cash flows and liquidity.

• Accounting for our revenues, costs and the valuation of acquired mineral reserves involves significant estimates. As further described in “Critical Accounting Estimates” under “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations,” and in “Use of Estimates in the Preparation of Financial Statements,” and “Revenue Recognition,” within Note 1 of the “Notes to the Consolidated Financial Statements,” accounting for our contract-related revenues and costs, as well as the valuation of acquired mineral reserves, requires management to make a variety of significant estimates and assumptions. These assumptions and estimates may change significantly in the future and could result in the reversal of previously recognized revenue and profit or cause material impairment charges. Such changes could have a material adverse effect on our financial position and results of operations.

• Earnings may be impacted by impairment charges for goodwill and intangible assets. We carry a significant amount of goodwill and identifiable intangible assets on our consolidated balance sheets. We assess goodwill for impairment annually as of November 1 and more frequently when events and circumstances occur that indicate a possible impairment. We also review identifiable intangible assets for impairment whenever events or changes in circumstances indicate the carrying amount of an asset group may not be recoverable. See “Long-Lived Assets” and “Goodwill” in Note 1 of the “Notes to the Consolidated Financial Statements” for additional information regarding our goodwill and identifiable intangible assets. If we determine that the carrying amount of goodwill or our unamortized intangible assets exceeds their fair value, we would be required to recognize a non-cash impairment charge, which could have a material adverse effect on our business, results of operations or financial condition.

• A change in tax laws or regulations of any federal, state or international jurisdiction in which we operate could increase our tax burden and otherwise adversely affect our financial position, results of operations, cash flows and liquidity. We continue to assess the impact of various U.S. federal, state, local and international legislative proposals that could result in a material increase to our U.S. federal, state, local and/or international taxes. We cannot predict whether any specific legislation will be enacted or the terms of any such legislation. However, if such proposals were to be enacted, or if modifications were to be made to certain existing regulations, the consequences could have a material adverse impact on us, including increasing our tax burden, increasing our cost of tax compliance or otherwise adversely affecting our financial position, results of operations, cash flows and liquidity.

• We may be exposed to liabilities under the FCPA and any determination that we or any of our subsidiaries has violated the FCPA could have a material adverse effect on our business. The FCPA generally prohibits companies and their affiliates from making improper payment to non-U.S. officials for the purpose of obtaining or retaining business. Our internal policies, procedures and Code of Conduct mandate compliance with these anti-corruption laws. Despite our training and compliance programs, we cannot provide assurance that our internal policies and procedures will always protect us from violation of such anti-corruption laws committed by our affiliated entities or their respective officers, directors, employees and agents. We could also face fines, sanctions and other penalties from authorities in the relevant foreign jurisdictions, including prohibition of participating in or curtailment of business operations in those jurisdictions and the seizure of certain of our assets. Our customers in those jurisdictions could also seek to impose penalties or take other actions adverse to our interest. In addition, we could face other third-party claims by, among others, our stockholders, debt holders or other interest holders or constituents. Violations of FCPA laws, allegations of such violations and/or disclosure related to any relevant

Table of Contents

investigation could have a material adverse impact on our financial position, results of operations, cash flows and liquidity for reasons including, but not limited to, an adverse effect on our reputation, our ability to obtain new business or retain existing business, to attract and retain employees, to access the capital markets and/or could give rise to an event of default under the agreements governing our debt instruments.

• If we identify material weaknesses or otherwise fail to maintain an effective system of internal controls, we may not be able to accurately and timely report our financial results, investors may lose confidence in us and the market price of our common stock may decrease. We may not be able to accurately and timely report our financial results and/or we may not be able to detect errors on a timely basis if in the future we: (1) identify one or more material weaknesses in our internal control over financial reporting; (2) are unable to successfully remediate any such material weaknesses; (3) are unable to comply with the requirements of Section 404 in a timely manner; or (4) are unable to assert, or our independent registered public accounting firm is unable to attest, that our internal control over financial reporting is effective. This could result in: (i) our financial statements being materially misstated; (ii) investors losing confidence in the accuracy and completeness of our financial reports; (iii) the market price of our common stock decreasing; (iv) our liquidity and access to the capital markets being adversely affected; and (v) our inability to maintain compliance with applicable stock exchange listing requirements and debt covenants. We could also become subject to stockholder or other third-party litigation as well as investigations by the stock exchange on which our securities are listed, the SEC or other regulatory authorities, which could require additional financial and management resources and could result in fines, penalties, trading suspensions or other remedies. Further, because of its inherent limitations, even our effective internal controls over financial reporting may not prevent or detect all misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in our conditions, or that the degree of compliance with our policies or procedures may deteriorate.

RISKS RELATED TO INFORMATION TECHNOLOGY

• Changes to our outsourced software or infrastructure vendors as well as any sudden loss, breach of security, disruption or unexpected data or vendor loss associated with our information technology systems could have a material adverse effect on our business. We rely on third-party software and infrastructure to run critical accounting, project management and financial information systems. If software or infrastructure vendors decide to discontinue further development, integration or long-term maintenance support for our information systems, or there is any system interruption, delay, breach of security, loss of data or loss of a vendor, we may need to migrate some or all of our accounting, project management and financial information to other systems. These disruptions could increase our operational expense as well as impact the management of our business operations, which could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.

• Cybersecurity incidents or breaches of our information technology environment could result in business interruptions, remediation costs and/or legal claims . We have experienced and may continue to face cybersecurity incidents, including ransomware and unauthorized access, aimed at misappropriating information, corrupting data or causing operational disruptions. Additionally, the increased prevalence and use of artificial intelligence may heighten the risk that we may be subject to cybersecurity incidents in the future. If a failure of our cybersecurity defense measures were to occur, or if software or third-party vendors that support our information technology environment are compromised, it could have a negative impact to our business and result in business interruptions, remediation costs and/or legal claims, which could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.

• Artificial intelligence presents risks and challenges that could have a material adverse effect on our business, results of operations and financial condition. We have developed pilot programs to implement certain third-party generative artificial intelligence (“AI”) and predictive analytics tools into our systems for specific purposes. These tools presently include, without limitation, (i) a knowledge retention tool, (ii) a risk assessment tool and (iii) a virtual assistant tool. There is a risk that such AI tools (or AI tools used without Company approval) will be used in a manner that does not adhere to our AI policy and/or may be misused by our employees, vendors, or other third parties engaged by us. This, in turn, could result in the loss of confidential or proprietary information and subject us to competitive or reputational harm, as well as potential regulatory investigations/actions and/or legal liability. Additionally, we may not be able to control, and may lack visibility into, how third-party AI tools use, or AI features incorporated into third-party products that we use, are developed or maintained, or how such tools use, disclose and/or protect the data we input, even where we have sought contractual protections with respect to these matters. Further, AI algorithms may be flawed, and the data used to train AI tools may be inaccurate, incomplete or biased. As a result, the content, analysis or recommendations that these tools produce may be inaccurate, incomplete or biased and our use of this information may have a material adverse effect on our business, results of operations and financial condition. Additionally, we expect that there will continue to be new laws or regulations

Table of Contents

concerning the use of AI that could impose on us certain obligations and costs related to monitoring and compliance. Finally, we may not be successful in, and may lack sufficient resources to pursue, adopting and implementing AI tools to the same extent as our competitors. If we are unable to adopt and implement these tools in a cost-effective, timely manner or at all, it could cause competitive harm and/or have a material adverse effect on our business, results of operations and financial condition.

RISKS RELATED TO OUR CAPITAL STRUCTURE

• Failure to remain in compliance with covenants under our Credit Agreement, service our indebtedness, or fund our other liquidity needs could adversely impact our business. Our failure to comply with any of the restrictive or financial covenants would constitute an event of default under our Credit Agreement. Our failure to pay principal, interest or other amounts when due or within the relevant grace period on our 3.25% convertible senior notes due 2030 (the “3.25% Convertible Notes”), our 3.75% convertible senior notes due 2028 (the “3.75% Convertible Notes”) or our Credit Agreement would constitute an event of default under the indenture governing our 3.25% Convertible Notes, the indenture governing our 3.75% Convertible Notes or the Credit Agreement. A default under our Credit Agreement could result in (i) us no longer being entitled to borrow under such facility; (ii) termination of such facility; (iii) the requirement that any letters of credit under such facility be cash collateralized; (iv) acceleration of amounts owed under the Credit Agreement; and/or (v) foreclosure on any collateral securing the obligations under such facility. A default under the indenture governing our 3.25% Convertible Notes or the indenture governing our 3.75% Convertible Notes could result in acceleration of the maturity of the notes. If we are unable to service our debt obligations as a result of rising or high interest rates or any other reason or fund our other liquidity needs, we could be forced to curtail our operations, reorganize our capital structure (including through bankruptcy proceedings) or liquidate some or all of our assets in a manner that could cause holders of our securities to experience a partial or total loss of their investment in us.

• Servicing our debt requires a significant amount of cash, and we may not have sufficient cash flow from our business to pay our debt. Our ability to make scheduled payments of the principal of, to pay interest on or to refinance our indebtedness, including our 3.25% Convertible Notes and our 3.75% Convertible Notes and the obligations under our Credit Agreement, depends on our future performance, which is subject to economic, financial, competitive and other factors beyond our control. Additionally, borrowings under our Credit Agreement bear interest at a variable rate. As interest rates increase or remain high, our interest expense will also increase or remain high if we continue to borrow or increase our borrowings under the credit facility. Our business may not continue to generate sufficient cash flow from operations in the future to service our debt and make necessary capital expenditures. If we are unable to generate such cash flow, we may be required to adopt one or more alternatives, such as selling assets, restructuring debt or obtaining additional equity capital on terms that may be onerous or highly dilutive. Our ability to refinance our indebtedness will depend on the financial markets and our financial condition at such time. We may not be able to engage in any of these activities or engage in these activities on desirable terms, which could result in a default on our debt obligations, which could have a material adverse effect on our business and financial condition.

• Conversion of our 3.25% Convertible Notes and our 3.75% Convertible Notes may dilute the ownership interest of existing stockholders and may affect the trading price of our common stock. The 3.25% Convertible Notes and the 3.75% Convertible Notes are convertible at the option of the holders upon the occurrence of certain events and/or during certain periods. Upon conversion of the 3.75% Convertible Notes, we will pay or deliver, as the case may be, cash, shares of our common stock or a combination of cash and shares of our common stock, at our election. Upon conversion of the 3.25% Convertible Notes, we will settle the principal amount of the 3.25% Convertible Notes in cash, and any conversion premium in excess of the principal amount in cash, shares of our common stock or a combination of cash and shares of our common stock, at our election. The issuance of shares of our common stock upon conversion of our 3.25% Convertible Notes and our 3.75% Convertible Notes may dilute the ownership interests of existing stockholders. Any sales in the public market of our common stock issuable upon such conversion could adversely affect prevailing market prices of our common stock.

• The capped call transactions related to our 3.25% Convertible Notes and our 3.75% Convertible Notes may affect the value of our common stock. In connection with our 3.25% Convertible Notes offering and our 3.75% Convertible Notes offering, we entered into capped call transactions with option counterparties. The capped call transactions are expected generally to reduce the potential dilution to our common stock upon conversion of the 3.25% Convertible Notes and the 3.75% Convertible Notes and/or offset any cash payments we elect or are required to make in excess of the principal amount of converted notes, as the case may be. However, when the market price per share of our common stock exceeds the cap price of the capped call transactions ($79.83 for the capped call transactions related to the 3.75% Convertible Notes and $119.82 for the capped call transactions related to our 3.25% Convertible Notes), there would nevertheless be dilution and/or there would not be an offset

Table of Contents

of such cash payments, in each case, to the extent that such market price exceeds the cap price of the capped call transactions. Additionally, in connection with establishing the capped call transactions, the option counterparties may have entered into various derivative transactions with respect to our common stock. The option counterparties may modify their hedge positions by entering into or unwinding various derivatives with respect to our common stock and/or purchasing or selling our common stock or other securities of ours in secondary market transactions. This activity could cause or hinder an increase or a decrease in the market price of our common stock. The effect, if any, of these transactions and activities on the market price of our common stock will depend in part on market conditions and cannot be ascertained at this time, but these activities could adversely affect the market price of our common stock.

• We are subject to counterparty risk with respect to the capped call transactions. The option counterparties are financial institutions or affiliates of financial institutions, and we are subject to the risk that one or more of such option counterparties may default under the capped call transactions. Our exposure to the credit risk of the option counterparties is not secured by any collateral. Past global economic conditions, including increases in prevailing interest rates, have resulted in the actual or perceived failure or financial difficulties of many financial institutions. If any option counterparty becomes subject to bankruptcy or other insolvency proceedings, we will become an unsecured creditor in those proceedings with a claim equal to our exposure at that time under the capped call transaction with such option counterparty. Our exposure will depend on many factors but, generally, an increase in our exposure will be positively correlated to an increase in our common stock market price and in the volatility of the market price of our common stock. In addition, upon a default by an option counterparty, we may suffer adverse tax consequences and dilution with respect to our common stock. We can provide no assurance as to the financial stability or viability of any option counterparty.

• The price of our common stock historically has been volatile. Our stock price may continue to be volatile and subject to significant price and volume fluctuations in response to market and other factors, including the other factors discussed in “Risks Factors;” variations in our quarterly operating results from our expectations or those of securities analysts or investors; downward revisions in securities analysts’ estimates; and announcement by us or our competitors of significant acquisitions, strategic partnerships, joint ventures or capital commitments. In addition, the sale or the availability for sale of a large number of shares of common stock in the public market could cause the price of our common stock to decline.

• Delaware law and our charter documents may impede or discourage a takeover, which could reduce potential increases in the market price of our common stock. We are a Delaware corporation, and the anti-takeover provisions of Delaware law impose various impediments to the ability of a third party to acquire control of us, even if a change in control would be beneficial to our existing stockholders. In addition, our Board of Directors has the power, without stockholder approval, to designate the terms of one or more series of preferred stock and issue shares of preferred stock. The ability of our Board of Directors to create and issue a new series of preferred stock and certain provisions of Delaware law and our certificate of incorporation and bylaws could impede a merger, takeover or other business combination involving us or discourage a potential acquirer from making a tender offer for our common stock, which, under certain circumstances, could reduce potential increases in the market price of our common stock.

• Our bylaws include a forum selection clause, which could limit our stockholders’ ability to obtain a favorable judicial forum for disputes with us. Unless we consent in writing to the selection of an alternative forum, the Court of Chancery of the State of Delaware (or, if and only if the Court of Chancery of the State of Delaware lacks subject matter jurisdiction, any state court located within the State of Delaware or, if and only if all such state courts lack subject matter jurisdiction, the federal district court for the District of Delaware) shall be the sole and exclusive forum for the following types of actions or proceedings under Delaware statutory or common law: (a) any derivative action or proceeding brought on behalf of Granite; (b) any action asserting a breach of a fiduciary duty owed by any director, officer or other employee of Granite to Granite or its stockholders; (c) any action asserting a claim against Granite or any director or officer or other employee of Granite arising pursuant to any provision of the Delaware General Corporation Law, Granite’s certificate of incorporation or bylaws; (d) any action or proceeding to interpret, apply, enforce or determine the validity of Granite’s certificate of incorporation or bylaws (including any right, obligation, or remedy thereunder); (e) any action or proceeding as to which the Delaware General Corporation Law confers jurisdiction to the Court of Chancery of the State of Delaware; or (f) any action asserting a claim against Granite or any director or officer or other employee of Granite that is governed by the internal affairs doctrine, in all cases to the fullest extent permitted by law and subject to the court’s having personal jurisdiction over the indispensable parties named as defendants, except that the foregoing does not apply to suits brought to enforce a duty or liability created by the Exchange Act or any other claim for which the federal courts have exclusive jurisdiction. Additionally, unless we consent in writing to the selection of

Table of Contents

an alternative forum, the federal district courts of the United States of America shall be the exclusive forum for the resolution of any complaint asserting a cause of action arising under the Securities Act of 1933, subject to and contingent upon a final adjudication in the State of Delaware of the enforceability of such exclusive forum provision. The forum selection provision in our bylaws may limit our stockholders’ ability to pursue claims in a judicial forum of their choosing for disputes with us, our directors, officers or employees. It is possible that, notwithstanding the forum selection clause included in our bylaws, a court could rule in specific circumstances that such a provision is inapplicable or unenforceable, which could require that we defend claims in other forums.

RISKS RELATED TO CLIMATE CHANGE

• Physical, transition and regulatory risks related to climate change could have a material adverse impact on our business, financial condition and results of operations. Physical risks related to climate change, such as changing sea levels, temperature fluctuations, severe storms, and energy, supply chain and technological disruptions, could cause delays and increases in project costs, resulting in variability in our revenue and profitability, as well as potentially adverse impacts to our operating results and financial condition. In addition, growing public concern about climate change has resulted in the increased focus of local, state, regional, national and international regulatory bodies on greenhouse gas emissions and climate change issues. Legislation to regulate greenhouse gas emissions has periodically been introduced and passed by the U.S. Congress and the legislatures of various states in which we operate, and there has been a wide-ranging policy debate, both in the United States and internationally, regarding the regulation of greenhouse gas emissions. Such policy changes, including any enactment of increasingly stringent emissions or other environmental regulations, could increase the costs of supplies or projects for us and for our clients and, in some cases, delay or even prevent a project from going forward, thereby potentially reducing demand for our services. Consequently, this could have a material adverse effect on our business, financial condition and results of operations.

• We may be unable to achieve our sustainability commitments and targets which could result in the loss of investors and customers, a negative impact on our stock price, and damage to our reputation. We are committed to advancing our sustainability strategy. However, achievement of our sustainability commitments and targets is subject to risks and uncertainties, many of which are outside of our control. These risks and uncertainties include, but are not limited to: our ability to execute our operational strategies and achieve our goals within the currently projected costs and the expected timeframes; the availability and cost of alternative fuels and electric vehicles, availability of renewable energy; unforeseen design, operational and technological difficulties; the outcome of research efforts and future technology developments; compliance with, and changes or additions to, global, national, regional and local regulations, taxes, charges, mandates or requirements relating to greenhouse gas emissions, carbon costs or climate-related goals; labor-related regulations and requirements that restrict or prohibit our ability to impose requirements on third party contractors; adapting products to customer preferences and customer acceptance of sustainable supply chain solutions; and the actions of competitors and competitive pressures.

There is no assurance that we will be able to successfully implement our strategies and achieve our targets. If we are unable to meet our commitments and targets and appropriately address sustainability enhancement, we may lose investors, customers or partners, our stock price may be negatively impacted, our reputation may be negatively affected and it may be more difficult for us to compete effectively, all of which could have an adverse effect on our business, financial condition and results of operations, as well as on the price of our common stock.

In addition, new laws, regulations and policies relating to matters such as sustainability and climate change may be developed and formalized in the United States, which could entail specific, target-driven frameworks and/or disclosure requirements. Any failure, or perceived failure, by us to comply fully with developing interpretations of such laws and regulations could harm our business, reputation, financial condition and results of operations and require significant time and resources to make the necessary adjustments.

The foregoing list is not all-inclusive. There can be no assurance that we have correctly identified and appropriately assessed all factors affecting our business or that the publicly available and other information with respect to these matters is complete and correct. Additional risks and uncertainties not presently known to us or that we currently believe to be immaterial may also adversely affect us. These developments could have material adverse effects on our business, financial condition, results of operations and liquidity. For these reasons, the reader is cautioned not to place undue reliance on our forward-looking statements.

Item 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

General

We deliver infrastructure solutions for public and private clients primarily in the United States. We are one of the largest diversified, vertically integrated civil contractors and construction materials producers in the United States. Within the public sector, we primarily concentrate on infrastructure projects, including the construction of streets, roads, highways, mass transit facilities, airport infrastructure, bridges, dams, power-related facilities, utilities, tunnels, water well drilling and other infrastructure-related projects. Within the private sector, we perform various services such as site preparation, mining services and infrastructure services for commercial and industrial sites, railways, residential development, energy development, as well as provide construction management professional services. We own and lease aggregate reserves and own processing plants that are vertically integrated into our construction operations and we also produce construction materials for sale to third parties.

We have vertically integrated operations across Alaska, Arizona, California, Kentucky, Louisiana, Mississippi, Nevada, Oregon, Tennessee, Utah and Washington in addition to regional civil construction home markets in the Midwest, Florida and Texas. Our Construction segment also operates national businesses within the Tunnel division and the Federal division, which performs civil construction across the continental United States and Guam, the Industrial & Energy division, which primarily focuses on commercial solar construction projects, and the Layne division, which performs water well drilling, rehabilitation services and mineral exploration services.

Our reportable segments are the same as our operating segments and correspond with how our chief operating decision maker, or decision-making group (our “CODM”), regularly reviews financial information to allocate resources and assess performance. We previously identified our CODM as our Chief Executive Officer (“CEO”) and our Chief Operating Officer (“COO”). Following our COO's retirement on July 4, 2025, our CEO assumed sole responsibility as the CODM. Our reportable segments are: Construction and Materials. The Construction segment focuses on construction and rehabilitation of roads, pavement preservation, bridges, rail lines, airports, marine ports, dams, reservoirs, aqueducts, infrastructure and site development for use by the general public and water-related construction for municipal agencies, commercial water suppliers, industrial facilities and energy companies. It also provides construction of various complex projects including infrastructure and site development, mining, public safety, tunnel, solar, battery storage and other power-related projects. The Materials segment focuses on production and delivery of aggregates, asphalt concrete, liquid asphalt and recycled materials for internal use in our construction projects and for sale to third parties. See Note 21 of “Notes to the Consolidated Financial Statements” for additional information about our reportable segments.

The five primary economic drivers of our business are (i) the overall health of the U.S. economy including access to resources (labor, supplies and subcontractors); (ii) federal, state and local public funding levels; (iii) population growth resulting in public and private development; (iv) the need to build, replace or repair aging infrastructure; and (v) the pricing of certain commodity related products. A stagnant or declining economy will generally result in reduced demand for construction and construction materials in the private sector. This reduced demand increases competition for private sector projects and will ultimately also increase competition in the public sector as companies migrate from bidding on scarce private sector work to projects in the public sector. In addition, a stagnant or declining economy tends to produce less tax revenue for public agencies, thereby decreasing a source of funds available for spending on public infrastructure improvements. Some funding sources that have been specifically earmarked for infrastructure spending, such as diesel and gasoline taxes, are not as directly affected by a stagnant or declining economy, unless actual consumption is reduced or gasoline sales tax revenues decline consistent with fuel prices. However, even these can be temporarily at risk as federal, state and local governments take actions to balance their budgets. Conversely, increased levels of public funding as well as an expanding or robust economy will generally increase demand for our services and products and provide opportunities for revenue growth and margin improvement.

Critical Accounting Estimates

The financial statements included in “Item 8. Financial Statements and Supplementary Data” have been prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”). The preparation of these financial statements requires management to make estimates that affect the reported amounts of assets and liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. Our estimates and related judgments and assumptions are continually evaluated based on available information and experiences; however, actual amounts could differ from those estimates.

The following are our most critical accounting estimates that involve management judgment and can have significant effects on our reported results of operations.

Table of Contents

Revenue Recognition

Our revenue is primarily derived from construction contracts that can span several quarters or years in our Construction segment and from sales of construction related materials in our Materials segment. We recognize revenue in accordance with ASC Topic 606, Revenue from Contracts with Customers, and subsequently issued additional related ASUs. The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the forecasted revenue and cost to complete each project. Cost estimates for all of our significant projects use a detailed “bottom up” approach. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

• changes in costs of labor and/or materials;

• subcontractor costs, availability and/or performance issues;

• extended overhead and other costs due to owner, weather and other delays;

• changes in productivity expectations;

• changes from original design on design-build projects;

• our ability to fully and promptly recover on affirmative claims and back charges for additional contract costs;

• a change in the availability and proximity of equipment and materials;

• complexity in original design;

• length of time to complete the project;

• the availability and skill level of workers in the geographic location of the project;

• site conditions that differ from those assumed in the original bid;

• costs associated with scope changes; and

• the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit and gross profit margin from period to period. Significant changes in revenue and cost estimates, particularly in our larger, more complex, multi-year projects have had, and in the future could have, a significant effect on our profitability. Due to the number of factors that can contribute to changes in estimates of contract cost and profitability, the sensitivity of reported amounts to the assumptions underlying the estimate’s calculation is not reasonably available or meaningful. However, Note 3 of “Notes to the Consolidated Financial Statements” presents the impact material revisions in estimates had on the periods covered by this report.

Fair Value Measurement – Acquired Mineral Reserves

In 2025, we acquired businesses that included aggregates quarries with significant mineral reserves (See Note 2 of “Notes to the Consolidated Financial Statements”). We accounted for these transactions in accordance with ASC Topic 805, Business Combinations (“ASC 805”), and the preliminary purchase prices were allocated to assets acquired and liabilities assumed based on their estimated fair values as of the respective acquisition dates. This determination of fair value requires us to make estimates and use valuation techniques when a market value is not readily available.

We estimate the fair value of acquired mineral reserves using discounted cash flow models which involve significant assumptions such as the forecasted revenues, projected earnings before interest, taxes, depreciation and amortization (“EBITDA”) margins, and a discount rate. In determining the amount of reserves acquired, evaluations were completed by or under the supervision of qualified person(s) using industry best practices. See “Quarry Properties” under “Item 2. Properties,” for information on our reserves and methodology for estimating aggregate mineral resources and reserves. There are inherent uncertainties related to each of the above listed assumptions, and our judgment in applying them. These assumptions and estimates may change significantly in the future and could result in material impairment charges. Such changes could have a material adverse effect on our financial position and results of operations.

With all other factors remaining constant, a 0.5% decrease in the discount rate would cause a $19.5 million increase in the value of the acquired mineral reserves, while a 0.5% increase in the discount rate would cause a $17.6 million decrease in the value of the acquired mineral reserves. With all other factors remaining constant, a 1.0% change in the projected EBITDA margins would cause a $3.8 million increase or decrease in the value of the mineral reserves.

Table of Contents

Current Economic Environment and Outlook

Funding for our public work projects, which account for approximately 85% of our portfolio, is dependent on federal, state, regional and local revenues. At the federal level, the $1.2 trillion Infrastructure Investment and Jobs Act (“IIJA”) has increased federal highway, bridge and transit funding to its highest level in more than six decades with $550 billion in incremental funding over five years. The increased multi-year spending commitment improved the programming visibility for state and local governments and drove an increase in project lettings that started in 2023, and continued through 2025. With the IIJA ending in September of 2026, discussions have begun in Congress concerning a replacement bill.

At state, regional and local levels, voter-approved state and local transportation measures continue to support infrastructure spending. While each market is unique, we see a strong funding environment at the state and local levels aided by the IIJA. In California, our top revenue-generating state, despite overall budgetary concerns, a significant part of the state infrastructure spend is funded through Senate Bill 1 (SB-1), the Road Repair and Accountability Act of 2017, a 10-year, $54.2 billion program, which may only be used for transportation-related purposes, without any sunset provisions.

Over the last several years, inflation, supply chain and labor constraints have had a significant impact on the global economy including Granite and others in the construction industry in the United States. Recently, concerns over tariffs have been a major source of uncertainty in the economy. To date, we have not experienced a material financial impact due to tariffs. It is impossible to fully mitigate the potential impacts of the foregoing macro-economic factors and they may negatively impact us in the future. However, where practicable, we have applied proactive measures to mitigate these macro-economic factors, such as fixed forward purchase contracts of oil related inputs, energy surcharges, and adjustment of project schedules for constraints related to construction materials such as concrete.

Our Committed and Awarded Projects (“CAP”) balance continues to be strong with $7.0 billion at the end of the fourth quarter of 2025. Our CAP is supported by a positive public funding environment and strength in the private markets we serve, which we believe will provide further opportunities for continued CAP growth in 2026.

Acquisitions

Cinderlite

On October 3, 2025, we completed the acquisition of Cinderlite Trucking Corporation and related assets (“Cinderlite”) for $58.5 million in cash, subject to customary closing adjustments. We purchased all of the outstanding equity interest of Cinderlite, which is a construction materials, landscape supply, and transportation company in Carson City, Nevada. This acquisition aligns with our strategy of enhancing our vertical integration by strengthening our existing home markets.

Warren Paving

On August 5, 2025, we completed the acquisition of Slats Lucas, LLC and Warren Paving, Inc. (collectively, “Warren Paving”) for $540.0 million in cash, subject to customary closing adjustments. Warren Paving is a vertically-integrated asphalt contractor and aggregate producer with operations along the Gulf Coast and Mississippi River. This acquisition aligns with our strategy to expand our presence into new geographies with future growth opportunities while supporting our existing operations, particularly the Materials segment.

Papich Construction

On August 5, 2025, we completed the acquisition of Papich Construction Company, Inc. (“Papich Construction”) for $170.0 million in cash, subject to customary closing adjustments. Papich Construction is a provider of construction services and materials in California’s Central Coast and Central Valley regions. This acquisition aligns with our strategy of enhancing our vertical integration by strengthening our existing home markets.

Dickerson & Bowen, Inc.

On August 9, 2024, we acquired Dickerson & Bowen, Inc. (“D&B”). D&B is an aggregates, asphalt, and highway construction company serving central and southern Mississippi.

2025 Acquisition Financing

On August 5, 2025, we entered into the Fifth Amended and Restated Credit Agreement (the “Credit Agreement”), which provided for (1) a $600.0 million senior secured revolving credit facility (the “Revolver”), (2) a $600.0 million senior secured term loan (the “Initial Term Loan”) and (3) an additional $75.0 million senior secured term loan (“Delayed Draw Term Loan”).

The Warren Paving, Papich Construction and Cinderlite acquisitions were funded with proceeds from the Initial Term Loan, the Delayed Draw Term Loan, a $10.0 million draw on our Revolver and from cash on hand. The $10.0 million Revolver draw was repaid during the third quarter and the $75.0 million Delayed Draw Term Loan was repaid on October 31, 2025.

Table of Contents

See Note 1 and Note 2 of “Notes to the Consolidated Financial Statements” for further information about the above acquisitions and Note 14 of “Notes to the Consolidated Financial Statements” for further information about the debt transactions.

Results of Operations

Our operations are typically affected more by inclement weather conditions during the first and fourth quarters of our fiscal year which may alter our construction schedules and can create variability in our revenues and profitability.

Years Ended December 31,

(in thousands)

Total revenue

Gross profit

Selling, general and administrative expenses

Other costs, net (see Note 1 of “Notes to the Consolidated Financial Statements”)

Gain on sales of property and equipment, net

Operating income

Total other (income) expense, net

Amount attributable to non-controlling interests

Net income attributable to Granite Construction Incorporated

Revenue

Total Revenue by Segment

Years Ended December 31,

(dollars in thousands)

Construction

Materials

Total

Construction Revenue

Years Ended December 31,

(dollars in thousands)

Public

Private

Total

Construction revenue in 2025 increased by $239.7 million, or 7.0%, compared to 2024. This increase was primarily driven by $112.1 million of construction revenue from our recently acquired businesses, Warren Paving and Papich Construction, during 2025. Additionally, D&B construction revenue increased $23.6 million year-over-year. Our remaining Construction revenue increased year-over-year driven primarily by higher CAP entering the year.

Table of Contents

Materials Revenue

Years Ended December 31,

(dollars in thousands)

Aggregates

Asphalt

Other

Total

Materials revenue in 2025 increased by $177.2 million, or 29.9%, when compared to 2024. This increase was primarily driven by materials revenue from our recently acquired businesses, Warren Paving, Papich Construction and Cinderlite, of $106.4 million during 2025. Additionally, materials revenue increased due to higher sales volumes and prices in both aggregates and asphalt.

Committed and Awarded Projects

CAP consists of two components: (1) unearned revenue and (2) other awards. Unearned revenue includes the revenue we expect to record in the future on executed contracts, including 100% of our consolidated joint venture contracts and our proportionate share of unconsolidated joint venture contracts. We generally include a project in unearned revenue at the time a contract is awarded, the contract has been executed and to the extent we believe funding is probable. Contract options and task orders are included in unearned revenue when exercised or issued, respectively. Certain government contracts where funding is appropriated on a periodic basis are included in unearned revenue at the time of the award when it is probable the contract value will be funded and executed.

Other awards include the general construction portion of construction management/general contractor (“CM/GC”) contracts and awarded contracts with unexercised contract options or unissued task orders. The general construction portion of CM/GC contracts are included in other awards to the extent contract execution and funding is probable. Contracts with unexercised contract options or unissued task orders are included in other awards to the extent option exercise or task order issuance is probable. All CAP is in the Construction segment.

December 31,

(dollars in thousands)

Unearned revenue

Other awards

Total

December 31,

(dollars in thousands)

Public

Private

Total

CAP of $7.0 billion at December 31, 2025 was $1.7 billion, or 32%, higher than December 31, 2024. The most significant additions to CAP during 2025 included $494 million for a highway project in Nevada, $350 million for a drainage improvement project in Illinois, $327 million for two federal projects, $232 million for a water infrastructure project in Nevada, and $225 million for a tunnel project in Kentucky, all of which are for customers in the public sector.

Non-controlling partners’ share of CAP as of December 31, 2025 and 2024 was $361.4 million and $331.1 million, respectively.

At December 31, 2025 and 2024, one contract with remaining CAP of $10.0 million or more per project had total forecasted losses with remaining revenue of $25.6 million, or 0.4% of total CAP, and $64.4 million, or 1.2% of total CAP, respectively. Provisions are recognized in the consolidated statements of operations for the full amount of estimated losses on uncompleted contracts whenever evidence indicates that the estimated total cost of a contract exceeds its estimated total revenue.

Table of Contents

Gross Profit

The following table presents gross profit by reportable segment for the respective periods:

Years Ended December 31,

(dollars in thousands)

Construction

Percent of segment revenue

Materials

Percent of segment revenue

Total gross profit

Percent of total revenue

Construction gross profit for the year ended December 31, 2025 increased by $83.2 million, or 16.9%, when compared to 2024, primarily due to higher revenue and improved project execution across our project portfolio. We also recognized more net increases from revisions in estimates due to claim settlements than in the prior year. For further discussion of projects with revisions in estimates which individually had an impact of $5.0 million or more on gross profit, see Note 3 of “Notes to the Consolidated Financial Statements.” Additionally, construction gross profit from our recently acquired businesses, Warren Paving and Papich Construction, was $11.8 million for the year ended December 31, 2025, including an immaterial amount of purchase accounting-related charges, such as step-up depreciation and intangible asset amortization. See Note 2 of “Notes to the Consolidated Financial Statements” for further information about acquisitions.

Materials gross profit for the year ended December 31, 2025 increased by $55.3 million, or 67.7%, when compared to 2024 and gross profit margin increased to 17.8%. The improvement in gross profit was primarily driven by higher volumes and sales prices in both aggregates and asphalt. The increase was also driven by gross profit from our recently acquired businesses, Warren Paving, Papich Construction, and Cinderlite, of $14.8 million for 2025, which included $7.2 million of purchase accounting-related charges such as step-up depreciation and intangible asset amortization. See Note 2 of “Notes to the Consolidated Financial Statements” for further information about acquisitions.

Selling, General and Administrative Expenses

The following table presents the components of selling, general and administrative expenses for the respective periods:

Years Ended December 31,

(dollars in thousands)

Salaries and related expenses

Incentive compensation

Stock-based compensation

Other selling, general and administrative expenses

Total selling, general and administrative expenses

Percent of revenue

Selling, general and administrative (“SG&A”) expenses include the costs for estimating and bidding, including offsetting customer reimbursements for portions of our selling/bid submission expenses (i.e., stipends), business development, materials facility permits, and costs related to our operational offices that are not allocated to direct contract costs and expenses related to our corporate functions. Other SG&A expenses include travel and entertainment, outside services, information technology, depreciation, occupancy, training, office supplies, changes in the fair market value of our non-qualified deferred compensation plan liability and other miscellaneous expenses. SG&A expenses can vary depending on the volume of projects in process and the number of employees assigned to estimating and bidding activities. As projects are completed or the volume of work slows down, we temporarily redeploy project employees to bid on new projects, moving their salaries and related costs from cost of revenue to selling expenses. SG&A expenses for 2025 increased $73.4 million compared to 2024, primarily due to $40.4 million of higher salaries and related expenses due to increased labor costs, as well as $26.2 million of increased incentive and stock-based compensation due to improved financial performance. Of the total increases, SG&A expenses from acquired businesses increased $11.6 million, including $3.3 million of purchase accounting related depreciation and intangible asset amortization.

Table of Contents

Other Costs, net

The following table presents other costs, net for the respective periods:

Years Ended December 31,

(in thousands)

Other costs, net

Other costs, net mainly consist of acquisition and integration costs and legal costs related to the defense of a former Company officer in his civil litigation with the SEC. Other Costs, net increased by $1.5 million when compared to 2024 primarily due to increased acquisition and integration costs in the current year, partially offset by lower costs associated with the defense of the former Company officer. The SEC and the Company's former officer reached an agreement in January 2026 that resolved the litigation. As a result, we do not expect to incur any further material costs related to this matter. See Note 2 of “Notes to the Consolidated Financial Statements” for further information about acquisitions.

Gain on Sales of Property and Equipment, net

The following table presents the gain on sales of property and equipment, net for the respective periods:

Years Ended December 31,

(in thousands)

Gain on sales of property and equipment, net

Gain on sales of property and equipment, net for the year ended December 31, 2025 increased by $11.4 million when compared to 2024 primarily due to the sale of a property in Utah in 2025.

Other (Income) Expense

The following table presents the components of other (income) expense, net for the respective periods:

Years Ended December 31,

(in thousands)

Loss on debt extinguishment

Interest income

Interest expense

Equity in income of affiliates, net

Other income, net

Total other (income) expense, net

During 2025, total other (income) expense, net improved $17.6 million primarily due to the $27.6 million loss on debt extinguishment not recurring in the current year. This was partially offset by $15.5 million of increased interest expense, net of interest income, due to borrowings under the the Initial Term Loan and Delayed Draw Term Loan in 2025.

Income Taxes

The following table presents the provision for income taxes for the respective periods:

Years Ended December 31,

(in thousands)

Provision for income taxes

Effective tax rate

Our effective tax rate decreased from 28.4% to 23.7% when compared to 2024 primarily due to a decrease in nondeductible debt extinguishment costs.

Table of Contents

Amount Attributable to Non-controlling Interests

The following table presents the amount attributable to non-controlling interests in consolidated subsidiaries for the respective periods:

Years Ended December 31,

(in thousands)

Amount attributable to non-controlling interests

The amount attributable to non-controlling interests represents the non-controlling owners’ share of the net (income) loss of our consolidated construction joint ventures. The increase during 2025 was primarily due to improved profitability on joint venture projects as well as the impact of net increases from revisions in estimates related to consolidated construction joint ventures (see Note 3 of “Notes to the Consolidated Financial Statements”).

Prior Years Comparison (2024 to 2023)

See Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations in our Annual Report on Form 10-K filed with the SEC on February 14, 2025.

Liquidity and Capital Resources

Our primary sources of liquidity are cash and cash equivalents, investments, available borrowing capacity under our Credit Agreement and cash generated from operations. We may also from time to time issue and sell equity, debt or hybrid securities or engage in other capital markets transactions or sell one or more business units or assets. See Note 14 of the “Notes to the Consolidated Financial Statements” for information on our debt.

Our material cash requirements include paying the costs and expenses associated with our operations, servicing outstanding indebtedness, making capital expenditures and paying dividends on our capital stock. We may also from time to time prepay or repurchase outstanding indebtedness, repurchase shares of our common stock or acquire assets or businesses that are complementary to our operations. See Note 2 and Note 17 of the “Notes to the Consolidated Financial Statements” for information on our recent acquisitions and share repurchases, respectively.

Our primary contractual obligations are as follows and are further discussed in the referenced “Notes to the Consolidated Financial Statements:”

• Asset retirement obligations - see Note 11, Property and Equipment, net

• Debt and the associated interest payments – see Note 14, Debt

• Operating lease and royalty future minimum payments – see Note 15, Leases

• Non-Qualified Deferred Compensation Plan obligations – see Note 16, Employee Benefit Plans

In addition to the obligations referenced above, as of December 31, 2025 we had $11.6 million of purchase commitments for equipment and other goods and services not directly connected with our construction contracts, which are individually greater than $50,000 and have an expected fulfillment date after December 31, 2025. Of this, approximately $10.0 million and $1.6 million will be paid in 2026 and 2027, respectively. There are no material purchase commitments in the periods thereafter.

We believe our primary sources of liquidity will be sufficient to meet our expected working capital needs, capital expenditures, financial commitments, cash dividend payments and other liquidity requirements associated with our existing operations for the next twelve months. We also believe our primary sources of liquidity, access to debt and equity capital markets and cash expected to be generated from operations will be sufficient to meet our long-term requirements and plans. However, there can be no assurance that sufficient capital will continue to be available or that it will be available on terms acceptable to us.

As of December 31, 2025, our cash and cash equivalents consisted of deposits and money market funds held with established national financial institutions and marketable securities consisting of commercial paper, corporate notes and bonds, Municipal notes and bonds and U.S. Government and agency obligations.

On August 5, 2025, we entered into the Credit Agreement, which provides for (1) a $600.0 million Revolver, (2) a $600.0 million Initial Term Loan and (3) an additional $75.0 million Delayed Draw Term Loan. On October 3, 2025, we drew the additional $75.0 million Delayed Draw Term Loan, all of which was repaid during 2025. As of December 31, 2025, the $600.0 million Initial Term Loan was outstanding and the total unused availability under our Revolver was $583.2 million, resulting from $16.8 million in issued and outstanding letters of credit and nothing drawn on the Revolver. See Note 14 of “Notes to the Consolidated Financial Statements.”

Table of Contents

As of December 31, 2025, one of the conditions permitting the holders of the 3.25% Convertible Notes to convert was met. Our common stock traded above 130% of the $77.88 conversion price for at least 20 trading days during the period of 30 consecutive trading days ending on December 31, 2025 (the last trading day of the calendar quarter). The holders of the 3.25% Convertible Notes have the right to convert through March 31, 2026, at which point we will re-evaluate whether the 3.25% Convertible Notes will continue to be convertible in the subsequent calendar quarter. In the event the holders of the 3.25% Convertible Notes elect to convert a portion, or all of their 3.25% Convertible Notes, the principal amount is required to be settled in cash. As a result, the $373.8 million principal amount has been classified as a current liability as of December 31, 2025 in the consolidated balance sheet. Any conversion premium will be satisfied with cash, shares of our common stock or a combination of cash and shares of our common stock, at our election. At current market prices of our common stock, we do not expect holders to elect to convert their notes as the trading price of the notes in the secondary market exceeds the value a holder would receive upon conversion of such notes. In the unlikely event a holder elects to convert, we would use cash on hand or draw on our Revolver as needed.

In evaluating our liquidity position and needs, we also consider cash and cash equivalents held by our consolidated construction joint ventures (“CCJVs”). The following table presents our cash, cash equivalents and marketable securities, including amounts from our CCJVs, as of the respective dates:

December 31,

(in thousands)

Cash and cash equivalents excluding CCJVs

CCJV cash and cash equivalents (1)

Total consolidated cash and cash equivalents

Short-term marketable securities (2)

Long-term marketable securities (2)

Total cash, cash equivalents and marketable securities

(1) The volume and stage of completion of contracts from our CCJVs may cause fluctuations in joint venture cash and cash equivalents between periods. The assets of each consolidated and unconsolidated construction joint venture relate solely to that joint venture. The decision to distribute joint venture assets must generally be made jointly by a majority of the members and, accordingly, these assets, including those associated with estimated cost recovery of customer affirmative claims and back charge claims, are generally not available for the working capital needs of Granite until distributed.

(2) All marketable securities were classified as held-to-maturity and consisted of commercial paper, corporate notes and bonds, Municipal notes and bonds and U.S. Government and agency obligations as of December 31, 2025 and U.S. Government and agency obligations as of December 31, 2024.

Granite’s portion of CCJV cash and cash equivalents was $90.6 million and $106.0 million as of December 31, 2025 and 2024, respectively. Excluded from the table above is $35.0 million and $28.7 million as of December 31, 2025 and 2024, respectively, of Granite’s portion of unconsolidated construction joint venture cash and cash equivalents.

Capital Expenditures

Major capital expenditures are typically for aggregate and asphalt production facilities, aggregate reserves, construction equipment, buildings and leasehold improvements and investments in our information technology systems. The timing and amount of such expenditures can vary based on the progress of planned capital projects, the type and size of construction projects, changes in business outlook and other factors. During the year ended December 31, 2025, we had capital expenditures of $138.3 million, compared to $136.4 million during 2024, a increase of $1.9 million. We currently anticipate 2026 capital expenditures to be between approximately $140 million and $160 million, including approximately $50 million in planned strategic materials investments.

Cash Flows

Years Ended December 31,

(in thousands)

Net cash provided by (used in):

Operating activities

Investing activities

Financing activities

Table of Contents

Operating activities

As a large infrastructure contractor and construction materials producer, our revenue, gross profit and the resulting operating cash flows can differ significantly from period to period due to a variety of factors, including project progression toward completion, outstanding contract change orders and affirmative claims, and the payment terms of our contracts. Additionally, operating cash flows are impacted by the resolution of uncertainties inherent in the complex nature of the construction work we perform, including claim and back charge settlements. Our working capital assets result from both public and private sector projects. Customers in the private sector can be slower paying than those in the public sector; however, private sector projects generally have higher gross profit as a percentage of revenue. While we typically invoice our customers on a monthly basis, our construction contracts frequently provide for retention that is a specified percentage withheld from each payment by our customers until the contract is completed and the work accepted by the customer.

Cash provided by operating activities of $468.9 million during 2025 represents a $12.6 million increase in cash provided by operating activities when compared to 2024. The change was primarily attributable to a $93.0 million increase in net income after adjusting for non-cash items. This was partially offset by a $57.4 million decrease in cash provided by working capital, which includes receivables, net contract assets, inventories, other assets, accounts payable and accrued expenses and other liabilities. Additionally, distributions from, net of contributions to, unconsolidated construction joint ventures and affiliates decreased $23.0 million from 2024.

Investing activities

Cash used in investing activities of $993.7 million during 2025 represents a $765.2 million increase in cash used in investing activities when compared to 2024. The change was primarily due to a $643.2 million increase in cash used related to business acquisitions (see Note 3 of “Notes to the Consolidated Financial Statements”) along with an increase of $140.2 million in cash used in purchases of marketable securities, net of maturities. This increase was slightly offset by a $19.0 million increase in proceeds from sales of property and equipment.

Financing activities

Cash provided by financing activities of $475.7 million during 2025 represents a $542.8 million increase in cash provided by financing activities when compared to 2024. The change was primarily due to a $589.9 million increase in proceeds from debt issuances, net of debt repayments and related charges. See Note 14 to “Notes to the Consolidated Financial Statements” for further information about our debt transactions and our credit facility. The year over year increase in cash provided by financing activities was slightly offset by an increase in distributions to, net of contributions from, non-controlling partners, of $48.3 million.

Derivatives

We recognize derivative instruments as either assets or liabilities in the consolidated balance sheets at fair value using Level 2 inputs. See Note 8 to “Notes to the Consolidated Financial Statements” for further information. The capped call transactions related to the 3.75 % Convertible Notes and 3.25 % Convertible Notes were recorded to equity on our consolidated balance sheets based on the cash proceeds. See Note 14 to “Notes to the Consolidated Financial Statements” for further information.

Surety Bonds and Real Estate Mortgages

We are generally required to provide various types of surety bonds that provide an additional measure of security under certain public and private sector contracts. At December 31, 2025, approximately $3.9 billion of our $7.0 billion CAP was bonded. Performance bonds do not have stated expiration dates; rather, we are generally released from the bonds when the obligations of the underlying contract have been fulfilled. The ability to maintain bonding capacity requires that we maintain cash and working capital balances satisfactory to our sureties.

Our investments in real estate ventures are subject to mortgage indebtedness. This indebtedness is non-recourse to Granite but is recourse to the real estate venture. The terms of this indebtedness are typically renegotiated to reflect the evolving nature of the real estate projects as they progress through acquisition, entitlement, development and leasing. Modification of these terms may include changes in loan-to-value ratios requiring the real estate venture to repay portions of the debt. Our equity-method investments in our foreign affiliates are subject to local bank debt primarily for equipment purchases. This debt is non-recourse to Granite, but it is recourse to the affiliates. The debt associated with our equity-method investments is included in Note 9 of “Notes to the Consolidated Financial Statements.”

Covenants and Events of Default

Our Credit Agreement requires us to comply with various affirmative, restrictive and financial covenants, including the financial covenants described below. Our failure to comply with these covenants would constitute an event of default under the Credit Agreement. Additionally, the 3.25 % Convertible Notes and 3.75 % Convertible Notes are governed by the terms

Table of Contents

and conditions of their respective indentures. Our failure to pay principal, interest or other amounts when due or within the relevant grace period on our 3.25 % Convertible Notes, our 3.75 % Convertible Notes or our Credit Agreement would constitute an event of default under the 3.25 % Convertible Notes indenture, the 3.75 % Convertible Notes indenture or the Credit Agreement. A default under our Credit Agreement could result in (i) us no longer being entitled to borrow under such facility; (ii) the termination of such facility; (iii) the requirement that any letters of credit under such facility be cash collateralized; (iv) the acceleration of amounts owed under the Credit Agreement; and/or (v) the foreclosure on any collateral securing the obligations under such facility. A default under the 3.25 % Convertible Notes indenture or the 3.75 % Convertible Notes indenture could result in acceleration of the maturity of the notes.

The financial covenants under the terms of the Credit Agreement require the maintenance of a minimum Consolidated Interest Coverage Ratio and a maximum Consolidated Leverage Ratio. As of December 31, 2025, we were in compliance with the covenants in the Credit Agreement.

Share Repurchase Program

As announced on February 3, 2022, on February 1, 2022, the Board of Directors authorized us to purchase up to $300.0 million of our common stock at management’s discretion (the “2022 authorization”). During the year ended December 31, 2025 and 2024, we repurchased 300,200 shares and 524,800 shares, respectively, under the 2022 authorization and $157.6 million remained available under the 2022 authorization as of December 31, 2025.

The specific timing and amount of any future repurchases will vary based on market conditions, securities law limitations and other factors.

Recently Issued and Adopted Accounting Pronouncements

See Note 1 of “Notes to the Consolidated Financial Statements” under the caption Recently Issued and Adopted Accounting Pronouncements.